Terms & Conditions

1. Acceptance of Terms

By accessing or using the website of P.R. Engineering & Construction ("Company," "we," "us," or "our"), or by engaging our services, you agree to comply with and be bound by these Terms and Conditions. If you do not agree with any part of these terms, you must refrain from using our website or services.

2. Scope of Services

P.R. Engineering & Construction specializes in industrial and commercial construction services including but not limited to:

• Structural steelwork fabrication and erection
• Civil construction and site development
• Industrial plant setup and commissioning
• Piping, mechanical, and electrical installations
• Crane and heavy equipment operations
• Project management and consultation

The exact scope of work for each project shall be defined in the respective service agreement, purchase order, or contract executed between the Company and the Client.

3. Quotations & Pricing

All quotations provided by the Company are valid for a period of 30 days from the date of issue unless otherwise stated. Prices are subject to change based on:

• Fluctuations in raw material costs
• Changes in project scope requested by the Client
• Regulatory or compliance-related changes
• Force majeure or unforeseen site conditions

Any additional work beyond the agreed scope shall be billed separately with prior written consent from the Client.

4. Payment Terms

Unless otherwise agreed in writing:

• An advance payment of 30–50% of the total project value is required before commencement of work.
• Progress payments shall be made as per mutually agreed milestones.
• Final payment is due within 15 days of project completion and Client acceptance.
• Delayed payments may attract an interest charge of 1.5% per month on the outstanding amount.

5. Project Timelines & Delays

P.R. Engineering & Construction is committed to completing all projects within the agreed timeline. However, the Company shall not be held liable for delays arising from:

• Client-side delays in approvals, site access, or material supply
• Adverse weather conditions or natural disasters
• Government regulations, strikes, or civil disturbances
• Pandemic-related restrictions or supply chain disruptions

In the event of delay, the Company shall inform the Client promptly and work to minimize any impact on the project schedule.

6. Warranty & Defect Liability

The Company provides a defect liability period of 12 months from the date of project handover, during which any defects arising from workmanship or materials supplied by the Company shall be rectified at no additional cost.

This warranty does not cover damage resulting from misuse, unauthorized modifications, normal wear and tear, or causes beyond the Company's control.

7. Safety & Compliance

P.R. Engineering & Construction adheres to all applicable health, safety, and environmental regulations. The Client agrees to:

• Provide safe and accessible working conditions at the project site
• Obtain all necessary permits, licenses, and approvals
• Comply with all safety protocols recommended by the Company

8. Limitation of Liability

To the maximum extent permitted by law, the Company's total liability under any contract shall not exceed the total contract value. The Company shall not be liable for:

• Indirect, incidental, or consequential damages
• Loss of profits, revenue, or business opportunities
• Damages arising from Client-supplied drawings, specifications, or materials

9. Intellectual Property

All designs, drawings, engineering documents, and proprietary methods developed by P.R. Engineering & Construction remain the exclusive intellectual property of the Company. They shall not be reproduced, shared, or used for any purpose other than the agreed project without prior written consent from the Company.

10. Termination

Either party may terminate the agreement by providing 30 days written notice. In the event of termination:

• The Client shall pay for all work completed and materials procured up to the date of termination.
• The Company shall return any Client-owned materials and documents in its possession.
• Termination does not release either party from obligations already accrued.

11. Dispute Resolution

Any disputes arising from or in connection with these terms shall first be resolved through amicable negotiation. If unresolved, the dispute shall be referred to arbitration in accordance with the Arbitration and Conciliation Act, 1996 of India. The arbitration shall be conducted in English, and the seat of arbitration shall be in the jurisdiction of the Company's registered office.

12. Governing Law

These Terms and Conditions shall be governed by and construed in accordance with the laws of India. Any legal proceedings shall be subject to the exclusive jurisdiction of the courts at the location of the Company's registered office.

13. Website Usage

The content provided on this website is for general informational purposes only. While we make every effort to keep the information accurate and up-to-date:

• The Company makes no warranties or representations regarding the completeness, accuracy, or reliability of website content.
• Project images and descriptions are representative and may vary from actual deliverables.
• We reserve the right to modify, update, or remove website content without prior notice.

14. Amendments

P.R. Engineering & Construction reserves the right to update or modify these Terms and Conditions at any time without prior notice. The latest version will always be available on our website. Continued use of our services constitutes acceptance of the revised terms.